Terms and Conditions – Supply and Install
1.1 In these conditions:
‘Acknowledgement of the Quotation” means the countersigned duplicate of the Quotation.
‘Additional Works’ has the meaning given in clause 6.1.
‘Buyer’ means the ‘person’ ‘firm’ or ‘company’ named in the Quotation as the customer.
‘Completion Date’ the agreed date for completion of the Works.
‘Conditions’ means the standard terms and conditions set out in this document and (unless the context otherwise requires) include any special terms and conditions agreed in Writing between the Buyer and the Seller and/or as set out in the Quotation.
‘Contract’ means the contract for the carrying out of the Works, consisting of the Quotation, any Acknowledgement of the Quotation, if relevant, (and any documents referred to therein) and these Conditions.
‘Due Date’ has the meaning given in clause 5.1.
‘Goods’ means the goods (including any instalment of the goods or any parts for them), which the Seller is to supply as set out in the Quotation.
‘Material’ means all designs, drawings, models, plans, specifications, design details, photographs, brochures, reports, notes of meetings, CAD materials, calculations, data, databases, schedules, programmes, bills of quantities, budgets and any other materials provided in connection with the Works and all updated, amendments, additions and revisions to them and any works, designs, or inventions incorporated or referred to in them for any purpose.
‘Quotation’ means the Seller’s quotation for the Works.
‘Permitted Uses’ means the design, construction, completion, reconstruction, modification, refurbishment, development, maintenance, facilities management, funding, disposal, letting, fitting-out, advertisement, decommissioning, demolition, reinstatement, building information modelling and repair of the property or properties which are the subject of the Works.
‘Price’ has the meaning given in clause 4.1. plus any additional payment due under clause 7.2 below.
‘Seller’ means WHITESALES LIMITED (registered in England and Wales under number 08482222).
‘Site’ means the site where the Works are carried out.
‘Works’ means the supply and installation of the Goods and any other additional works agreed to be carried out under the Contract.
‘Writing’ includes e-mails, cable, facsimile transmission and comparable means of communication, provided that where the term is used in the context of an amendment, substitution or variation to the Conditions.
1.2 Any reference in these Conditions to any provision of a statue, regulation, order or other form of legislation is construed as a reference to that provision as amended re-enacted or extended from time-to-time.
1.3 The headings in these Conditions are for convenience only and shall not affect their interpretation.
2. Seller’s Obligations
2.1 These Conditions shall govern the Contract to the exclusion of any other terms and conditions.
2.2 The Seller shall carry out the Works in a good and workmanlike manner and complete the Works in accordance with the Contract using materials and workmanship herein specified or otherwise of a good and suitable standard and which are not generally regarded as deleterious.
2.3 If the Works include any design to be carried out by the Seller, any such design shall be carried out employing the standards of reasonable skill and care to be expected of a properly qualified and competent engineer or its equivalent profession experienced in carrying out work of a similar scope, nature, timescale and complexity to the Works.
2.4 No variation to the Contract shall be binding unless agreed in Writing between the authorised representatives of the Seller and the Buyer.
2.5 The Seller may appoint sub-consultants to perform any or all of the Works, but shall be liable for the acts and defaults of all such sub-consultants as if they were its own acts and defaults, and shall not be relieved of any obligation hereunder by reason of the use or appointment of sub-consultants.
2.6 The Seller’s employees or agents are not authorised to make any representations concerning the Works unless confirmed by the Seller in Writing. In entering into the Contract the Buyer acknowledges that it does not rely on and waives any claim for breach of, any such representations, which are not so confirmed.
2.7 Any typographical, clerical or other error or omission in any document or information issued by the Seller shall be subject to correction without any liability on the part of the Seller.
3. Orders and Specifications
3.1 The Buyer shall be responsible to the Seller for giving the Seller any necessary information relating to the Works within a sufficient time to enable the Seller to perform the Contract in accordance with its terms.
3.2 The Seller requires a minimum period of two weeks following acceptance of the Quotation in order to complete any necessary design and relevant drawings. Approval and/or review of any design, specification or similar matter by the Buyer or its representatives, whether occurring prior to or following the date of acceptance of the Quotation shall constitute acceptance that the design satisfies the requirements of the Contract.
3.3 Following approval by the Buyer of the drawings, a further 6 – 8 weeks is required by the Seller for the manufacture and delivery of the Goods prior to installation.
3.4 The quantity, quality and description of and any specification for the Goods shall be those set out in the Quotation and unless otherwise expressly set out therein the Seller gives no warranty that the Goods will conform to any particular standard specification or test.
3.5 No Contract shall be cancelled or terminated by the Buyer except with the agreement in Writing of the Seller and on terms that the Buyer shall indemnify the Seller in full against all loss (including loss of profit), costs (including the cost of all labour and materials used), damages, charges and expenses incurred by the Seller as a result of such cancellation or termination.
3.6 In addition to any other rights and remedies which the Seller may have, the Seller may at any time by notice in Writing to the Buyer immediately terminate the whole or any part of the Seller’s engagement under the Contract without any liability to the Buyer for any sums whatsoever incurred because of such termination.
4. Price of the Works
4.1 The price of the Works shall be the price set out in the Quotation or, where no prices have been quoted (or a quoted price is no longer valid), the price listed in the Seller’s published price list current at the date of acceptance of the Quotation (the ‘Price’). The Price is valid for 30 days or until earlier acceptance by the Buyer, after which time the Price may be altered by the Seller without notice to the Buyer.
4.2 The Price does not include the cost of the provision of any additional contract documents such as collateral warranties. For the avoidance of doubt additional contract documents such as collateral warranties, will be provided at the Seller’s discretion and no such documents (including any requested warranties) will be provided unless and until the Price has been paid in full. In the event any warranty (or any other document) is supplied to the Buyer before the Price has been paid in full to the Seller, the Buyer will have no right to rely on such document(s) provided unless and until the Price has been paid in full.
4.3 Unless otherwise expressly set out in the Quotation, the Price does not include the removal of existing units, (eg: rooflights, roof edge trims etc), cleaning or removal of protection or protective equipment including but not limited to, access equipment and safety barriers, or the provision of additional protection.
4.4 The Price is exclusive of any applicable value added tax, which the Buyer shall be additionally liable to pay the Seller.
4.5 The Price, and or any amounts quoted or invoiced are in £GBP unless specifically agreed otherwise in writing by a director of the Seller.
5. Terms of payment
5.1 Subject to any alternative payment terms set out in the Contract, the Price or any part thereof is due for payment on the date that the Buyer receives each invoice.
5.2. The final date for payment shall be 14 days after the Due Date (the “Final Date for Payment”).
5.3 In the event of a failure to pay any sum due to the Seller by the Buyer by the Final Date for Payment the Buyer shall have the right to:
5.3.1 suspend, following 7 days’ notice in writing, all or part of the Works. Upon the ending of a suspension the Buyer shall pay the Seller all reasonable costs of the suspension and shall grant the seller an extension of time for the period of the suspension;
5.3.2 charge the Buyer interest in accordance with the Late Payment of Commercial Debts (Interest) Act 1998 for the period of late payment.
5.4 All amounts due under the Contract shall be paid by the Buyer to the Seller in full without any set-off, counterclaim, deduction or withholding (other than any deduction or withholding of tax as required by law).
5.6 The Seller may at any time, without notice to the Buyer, set off any liability of the Buyer to the Seller against any liability of the Seller to the Buyer, whether either liability is present or future, liquidated or unliquidated, and whether or not either liability arises under the Contract. Any exercise by the Seller of its rights under this clause shall not limit or affect any other rights or remedies available to it under this agreement or otherwise.
5.7 The Seller shall be entitled to withhold any part of the Works until the Price or part of the Price has been paid in full by the Buyer in accordance with this clause 5.
6.1 The Buyer may, without invalidating the Contract, request an addition to or omission from or other change in the Works (“Additional Works”). As soon as reasonably practicable after receiving such a request, the Seller shall provide the Buyer with a written estimate of cost of the Additional Works. Such estimate is deemed to be accepted by the Buyer unless disputed in Writing within 7 days of the date of the estimate. The Seller shall in addition be entitled to reasonable direct loss and/or expense incurred by the Buyer or its agents as a result of any requested change.
6.2 The Seller is under no obligation whatsoever to accept a request to carry out Additional Works and may refuse to do so without giving a reason to the Buyer. Any such refusal shall not invalidate the Contract.
7. Extension to Completion Date
7.1 If it becomes apparent that the Works will not be completed by the Completion Date for reasons beyond the reasonable control of the Seller, including (but not limited to) compliance with any instruction of the Buyer, then the Seller shall notify the Buyer in writing who shall make such extension of time for completion as may be reasonable. The Buyer shall confirm in writing the extension of time granted and the revised Completion Date in line with the delay caused.
7.2 In the event of an extension of time to the Completion Date in accordance with clause 7.1, the Buyer shall pay to the Seller the additional costs incurred by the Seller (calculated where relevant in accordance with the rates in the Order) in addition to the Price. Such additional costs may include, but are not limited to, increased costs of labour, supervision, equipment or materials, reasonable overhead and profits).
8. Intellectual Property Rights
8.1 The Seller owns all intellectual property rights (including copyright) relating to the Material it produces, and these rights shall remain vested in the Seller.
8.2 The Seller grants to the Buyer from the date of the Contract an irrevocable, royalty-free, non-exclusive licence to use and to reproduce all Material prepared by, or on behalf of, the Seller for any purpose relating to the property or properties that are the subject of the Works, including any of the Permitted Uses.
8.3 The Seller shall not be liable for the use of the Material for any purpose other than that for which it was prepared and/or provided.
9. Materials and Equipment
9.1 The Buyer shall furnish all temporary facilities to the Site, including but not limited to the Site access, storage space, access scaffolding, floor covers, on-site security, parking, electrical services, lighting, heat, rubbish and recycling facilities.
9.2 Unfixed Goods and any other materials delivered to Site, or tools placed on or adjacent to the Works by the Seller, his servants, agent, suppliers or independent contractors shall not be removed from Site unless the Seller has given his prior written consent. The Buyer will be liable to pay the Seller the value of any items so removed and for the cost of any delays caused by such removal.
9.3 All Goods and any other materials and equipment shall remain the property of the Seller until all sums invoiced by the Seller have been paid to the Seller by the Buyer.
10. Insurance and Liability
10.1 The Buyer shall ensure that the Goods are covered by the insurance policy of the Buyer or other third party. Such insurance must be ‘all risk’ insurance on the full value of the Works together with materials delivered to the Site, materials stored at a temporary storage location away from the Site, and materials in transit.
10.2 Subject to clause 10.5, the Seller’s total liability to the Buyer in respect of all losses arising under or in connection with the Contract, whether in contract, tort (including negligence), breach of statutory duty, or otherwise, shall in no circumstances exceed the greater of £100,000 or the sum equivalent to ten times the Price. If the first sentence of this clause 10.2 is held to be invalid, the Seller’s total liability to the Buyer in respect of all losses arising under or in connection with the Contract shall in no circumstances exceed the level of professional indemnity insurance as stated in the Quotation.
10.3 In relation to any design to be carried out by the Seller, the Seller shall maintain professional indemnity insurance for an amount of at least that figure as stated in the Quotation or, in the absence of such figure, £2,000.000 (two million pounds) for any one claim for a period beginning on the date of the Contract and ending six years after completion of the Works, provided that such insurance is available at commercially reasonable rates and terms.
10.4 Nothing in the Contract shall limit or exclude the Seller’s liability for:
(a) death or personal injury caused by its negligence;
(b) fraud or fraudulent misrepresentation; or
(c) any other liability which cannot be limited or excluded by applicable law.
10.5 Subject to clause 10.4, the Seller shall not be liable to the Buyer, whether in contract, tort (including negligence), for breach of statutory duty, or otherwise, arising under or in connection with this agreement for:
(a) loss of profits;
(b) loss of sales or business;
(c) loss of agreements or contracts;
(d) loss of anticipated savings;
(e) loss of or damage to goodwill;
(f) loss of use or corruption of software, data or information; and
(g) any indirect or consequential loss.
11. Dispute Resolution
11.1 If a dispute or difference arises between the Buyer and Seller the parties agree to meet in good faith to attempt to resolve the dispute or difference that exists between them.
11.2 If any dispute or difference concerning the Works shall arise between the Buyer and Seller, such dispute or difference may be referred to adjudication such adjudication to be conducted in accordance with the Scheme for Construction Contracts Regulations (England and Wales) 1998 (as amended). For the purposes of such adjudication the parties agree that the nominating body for appointment of the adjudicator shall be the President or Vice President of the Royal Institute of Chartered Surveyors.
12. Governing law and Jurisdiction
12.1 The governing law of the Contract shall be the law of England and Wales.
12.2 The parties irrevocably agree that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim arising out of or in connection with the Works or the Contract (including non-contractual disputes or claims).
13. Third Party Rights
Nothing in the Contract confers or purports to confer on any third party any benefit or any right to enforce any term of the Contract pursuant to the Contracts (Rights of Third Parties) Act 1999.
If any provision or part-provision of the Contract is or becomes invalid, illegal or unenforceable, it shall be deemed modified to the minimum extent necessary to make it valid, legal and enforceable. If such modification is not possible, the relevant provision or part-provision shall be deemed deleted. Any modification to or deletion of a provision or part-provision under this clause shall not affect the validity and enforceability of the rest of the Contract.